HomeMy WebLinkAboutReso 07-2020 (19-1040)City of South San Francisco P.O. Box 711 (City Hall,
• 400 Grand Avenue)
South San Francisco, CA
• City Council
Resolution: RES 07-2020
File Number: 19-1040 Enactment Number: RES 07-2020
RESOLUTION AWARDING A CONSTRUCTION CONTRACT TO
SWINERTON BUILDERS OF SAN FRANCISCO, CALIFORNIA
FOR THE COMMUNITY CIVIC CAMPUS: PHASE I POLICE
STATION (PROJECT NO. PF1707; BID NO. 2633) IN AN
AMOUNT NOT TO EXCEED $47,563,300 AND AUTHORIZING A
TOTAL CONSTRUCTION BUDGET OF $52,553,015.
WHEREAS, the Community Civic Campus project completed a prequalification process for general
contractors; a total of four general contractors were prequalified and of those four only two submitted a
bid; Swinerton Building is the lowest responsible bidder; and
WHEREAS, Swinerton Builders will be subject to Prevailing Wage rates and compliance with City
Council approved Project Labor Agreement (PLA) executed on January 9, 2019 ; and
WHEREAS, total construction duration is (18) months; (540) calendar day construction period from date
of Notice to Proceed, which includes a clause for liquidated damages in the amount of $2,500.00 for
each calendar day delay in completion; and
WHEREAS, Swinerton Builders will comply with insurance requirements as outlined in Article 11 of the
General Conditions and provide corresponding Labor and Material Payment Bond and a Contractor's
Performance Bond in the amount of 100% of contract price; and
WHEREAS, City staff recommends execution of the Owner -Contractor agreement for the construction
of the Phase I Police Station project; and
WHEREAS, funding for this project is included in the City of South San Francisco's Community Civic
Campus program budget project.
NOW, THEREFORE, BE IT RESOLVED, by the City Council of the City of South San Francisco that
the City Council hereby awards a construction contract, a draft of which is attached hereto as Exhibit A,
for the Community Civic Campus: Phase I Police Station Project to Swinerton Builders of San
Francisco, California, in an amount not to exceed $47,563,300 conditioned on five hundred forty (540)
calendar day construction completion from Notice to Proceed, which will only be issued upon timely
execution of the Project contract and submission of all required documents, including but not limited to,
certificates of
City of South San Francisco Page 1
File Number. 19-1040
Enactment Number. RES 07-2020
insurance and endorsement, in accordance with the Project documents. Funding for the project is
primarily intended to be from the sale of bond, and completion of the work is contingent on the bond
sale, with the contractor to be paid for work performed.
BE IT FURTHER RESOLVED the City Council authorizes a total construction budget of $52,553,015.
BE IT FURTHER RESOLVED the City Council authorizes the Finance Department to establish the
Project Budget consistent with the information contained in the staff report.
BE IT FURTHER RESOLVED that the City Manager is hereby authorized to execute the agreement and
any other related documents on behalf of the City upon timely submission by Swinerton Builders of the
signed contract and all other documents, subject to approval by the City Attorney.
BE IT FURTHER RESOLVED that the City Council authorizes the City Manager to take any other
related actions consistent with the intention of the resolution.
At a meeting of the City Council on 1/8/2020, a motion was made by Councilmember Addiego, seconded by
Councilmember Nicolas, that this Resolution be approved. The motion passed.
Yes: 5 Mayor Garbarino, Vice Mayor Addiego, Councilmember Nagales, Councilmember
Nicolas, and Councilmember Matsumoto
Attest by
L W A IiWL—
I�sa Govea Acosta, City Clerk
City of South San Francisco Page 2
00500 - 1
OWNER-CONTRACTOR
Community Civic Campus, Phase 1 Police Station AGREEMENT
SECTION 00500
CITY OF SOUTH SAN FRANCISCO
OWNER-CONTRACTOR AGREEMENT
FOR THE
MEASURE W – COMMUNITY CIVIC CAMPUS PROJECT
THIS AGREEMENT made and entered into this 8, day of January, 2020,
between the CITY OF SOUTH SAN FRANCISCO, a municipal corporation and political
subdivision of the State of California, hereinafter called “CITY”, and SWINERTON
BUILDERS, hereinafter called “CONTRACTOR”1.
In consideration of the mutual covenants and agreements set forth herein,
CONTRACTOR and OWNER hereby agree as follows:
ARTICLE I
CONSTRUCTION
Subject to and in accordance with the terms of this Agreement, the
CONTRACTOR shall do all the work and furnish all the labor, services, materials and
equipment necessary to construct and complete, in accordance with the CONTRACT
DOCUMENTS (as hereinafter defined) in a good, workmanlike and substantial manner
and to the satisfaction of OWNER, SOUTH SAN FRANCISCO MEASURE W –
COMMUNITY CIVIC CAMPUS PROJECT ("PROJECT") upon that real property located
in South San Francisco, California more particularly depicted on Exhibit A (the "Site").
The PROJECT is that described and reasonably inferable from the drawings and
specifications and documents enumerated in Exhibit B. Such construction and
furnishing of labor, services, materials and equipment and the performance of
CONTRACTOR's other services and obligations required by the CONTRACT
DOCUMENTS are hereinafter referred to as the "WORK." The term "CONTRACT
DOCUMENTS" shall mean this Agreement, all of the items enumerated in Exhibit B and
all change orders or addenda issued with respect thereto, all the works and
improvements described, mentioned and set forth in the CONTRACT DOCUMENTS.
1.1The term "Contractor" as used herein is employed without distinction as to either number or gender
and shall include whenever the context shall permit all agents, representatives, employees, servants,
subcontractors and business or social invitees of Contractor.
Exhibit A
00500 - 2
OWNER-CONTRACTOR
Community Civic Campus, Phase 1 Police Station AGREEMENT
ARTICLE II
CONTRACT SUM
OWNER shall pay and CONTRACTOR shall accept as full compensation for the
WORK the sum ("CONTRACT SUM") set forth in Exhibit C.
ARTICLE III
TIME FOR PERFORMANCE
The Contractor shall complete all Work under the Contract Documents within (540)
calendar days of the effective date of the Notice to Proceed (“Scheduled Completion
Date”). The CONTRACTOR shall begin work within seven (7) calendar days from the
issuance of the Notice to Proceed, and shall diligently prosecute all of the work under
this Contract in all parts and requirements as defined in the Contract Documents.
In addition to the above;
1. All work associated with Communications Computer Room (Room 2409);
MPOE/Entrance Room (Room 1505); Radio Room (Room 1506); SWAT
Equipment Room (Room 1609); Dispatch (Room 2407; Supervisors Stations
(Room 2408) shall have final paint and temperature control (90) days prior to
Substantial Completion.
2. All close-out documentation shall be submitted to the Owner no later than (60)
days after Substantial Completion.
Section 3.1. Definitions.
The following are definitions as used in this Agreement:
The term "Completion Date" shall mean the date that all the WORK is substantially
complete.
The term “Direct Costs” shall mean the premium portion of overtime pay (i.e., the
amount in excess of their regular hourly rate), the labor cost of adding additional
workers to perform a task in excess of the number of workers CONTRACTOR
reasonably had planned to use, equipment costs in excess of equipment
CONTRACTOR reasonably had planned to use, and such other items of cost requested
in advance by CONTRACTOR and approved by OWNER.
The term "Excusable Delay" shall mean an actual delay in the performance of the
WORK on the Project’s Critical Path by CONTRACTOR caused by any of the following
only if such events are beyond the reasonable control of CONTRACTOR despite
00500 - 3
OWNER-CONTRACTOR
Community Civic Campus, Phase 1 Police Station AGREEMENT
CONTRACTOR having taken all reasonable attempts to prevent, avoid delay and
mitigate the effects thereof:
A. An act or omission of OWNER, or by an employee, agent or representative of
OWNER (other than by reason of the proper exercise of their respective rights,
duties and obligations under the CONTRACT DOCUMENTS) except as provided
in Section 7102 of the Public Contract Code; or
B. A fire, flood, unusually severe and abnormal weather conditions, rain in excess of
the anticipated average number of rain days per year over a ten (10) year period
based on historic weather data, war, embargo, sabotage, hurricane, earthquake,
tornado; or
C. An injunction that prevents performance of the W ORK, except for legal actions
initiated by CONTRACTOR, any subcontractor or supplier, or an injunction or
legal action that resulted from the acts or omissions of CONTRACTOR or any
subcontractor or supplier; or
D. A general strike, regulatory delays, strikes in or losses during transportation, or
other similar event which is beyond CONTRACTOR'S control.
The CONTRACTOR acknowledges that actual delays in activities that do not affect the
completion time ("non-critical delays") do not have any effect upon the Scheduled
Completion Date, and therefore, will not constitute an "Excusable Delay" nor be a basis
for changing the Scheduled Completion Date. The CONTRACTOR acknowledges that
time extensions will be granted only to the extent that Excusable Delays exceed the
available float in the PROJECT Schedule. Nothing herein excused CONTRACTOR
from its obligation to mitigate damages.
The term "Final Completion" shall mean the completion of all the WORK including
punch list items.
The term "Notice to Proceed" shall have the meaning described in Section 3.2 below.
The term "PROJECT" shall have the same meaning as that set forth in the General
Conditions.
The term "Scheduled Completion Date" shall mean and refer to the date set forth by
Section 3.2 below, as such date may be extended pursuant to Section 3.3 below, or by
Change Order.
The terms "Substantial Completion" and "Substantially Complete" shall have the
meaning set forth in Article 8 and Article 9 of the General Conditions.
00500 - 4
OWNER-CONTRACTOR
Community Civic Campus, Phase 1 Police Station AGREEMENT
Section 3.2. Notice to Proceed/Scheduled Completion Date.
The WORK under the Contract shall proceed pursuant to and in accordance with a
written notice from OWNER to CONTRACTOR to proceed (“Notice to Proceed”).
CONTRACTOR shall diligently commence performance of the WORK on the date
specified in the Notice to Proceed. CONTRACTOR shall complete performance of the
entire WORK (as defined in Article 8 and Article 9 of the General conditions) on or
before (540) consecutive calendar days after the date of issuance of the Notice to
Proceed (“Scheduled Completion Date”).
Section 3.3 Extension of Scheduled Completion Date.
(A) Excusable Delay
In the event that CONTRACTOR is actually delayed on the performance of the WORK
by any “Excusable Delay” which is an unforeseeable delay beyond the
CONTRACTOR’S control and not the fault of either party, then the Scheduled
Completion Date shall be extended for a period equal to the length of such Excusable
Delay. Such extension of time on account of an Excusable Delay shall not be allowed
unless applied for in writing by the CONTRACTOR within ten (10) calendar days of the
commencement of any such delay, or the CONTRACTOR’S reasonable notice of such
delay and the written approval of such extension of time is obtained from the Architect
or the OWNER. No verbal approval, either express or implied, or any grant of time
extension by OWNER or its agents shall be binding upon OWNER unless and until such
approval is expressly ratified in writing.
In the event the CONTRACTOR is delayed in the WORK by any such Excusable Delay,
the CONTRACTOR’S remedy shall be an extension of time. In no event shall
CONTRACTOR be entitled to a monetary payment over and beyond that, which is
specified in the OWNER-CONTRACTOR Agreement plus that which is specified by duly
executed change orders.
(B) Excusable and Compensable Delays
In the event of delay in the Work that is (i) the responsibility of the OWNER, (ii) is
unreasonable under the circumstances involved, and (iii) is not within the contemplation
of OWNER and CONTRACTOR at the time the PROJECT was awarded,
CONTRACTOR shall be entitled to an extension of time and compensation for such
delay in strict accordance with the provisions of this Section. No extension of time or
compensation shall granted unless the CONTRACTOR provides the OWNER with
written notice within ten (10) calendar days of the commencement of any such delay, or,
as the circumstance may be, CONTRACTOR’S reasonable notice of such delay. The
OWNER must approve of any extension of time or payment of compensation in writing.
No verbal approval, either express or implied, or any grant of time extension by
00500 - 5
OWNER-CONTRACTOR
Community Civic Campus, Phase 1 Police Station AGREEMENT
OWNER or its agents shall be binding upon OWNER unless and until such approval is
expressly ratified in writing.
CONTRACTOR’S remedy, in addition to the extension of time, shall be as follows, upon
CONTRACTOR’S demonstration that these costs were actually incurred as a direct
result of the delay:
a. Field or on-site labor shall be paid according to actual payroll data for the time of
the delay. No multipliers will be allowed unless previously approved in writing by
OWNER;
b. Idle field equipment will be priced at a daily rate calculated from the actual
invoice costs;
c. Idle field rental equipment will be priced at a daily rate calculated from the actual
invoice costs; and
d. Total mark up of items (a) through (c) above for overhead and profit, including all
levels of subcontractors and CONTRACTOR combined, shall not exceed 15%
cumulative. For the purposes of this section, overhead includes (1) all indirect
labor such as management, supervision, engineer and consulting, drafting,
estimating, secretarial and accounting; (2) all field office expenses, including
office supplies and equipment; (3) insurance and bonds; and (4) all corporate
office expenses.
In the event of delay in the WORK, which is not due to an Excusable Delay under
Section 3.3(A), or is not an Excusable and Compensable Delay under Section 3.3(B),
OWNER may direct that the WORK be accelerated by means of overtime, additional
crews or additional shifts or resequencing of the W ORK. All such acceleration
associated with an inexcusable delay, where the delay is attributable to the
CONTRACTOR, shall be at no cost to OWNER. In the event of Excusable Delay under
Section 3.3(A), or an Excusable and Compensable Delay under Section 3.3(B),
OWNER may similarly direct acceleration and CONTRACTOR agrees to perform the
WORK on the basis of reimbursement of Direct Cost plus a fee of five percent (5%) of
such costs but expressly waives any other compensation therefore. In the event of any
acceleration requested pursuant to this paragraph, CONTRACTOR shall provide
promptly a plan including recommendations for, in CONTRACTOR’s opinion, the most
effective and economical acceleration.
Section 3.4 Liquidated Damages.
A. Timely Completion
OWNER and CONTRACTOR recognize that time is of the essence of this Agreement,
and that OWNER will suffer financial loss if the work is not complete within the time
specified, plus any extensions of time authorized under Section 3.3 of this Agreement.
OWNER and CONTRACTOR further recognize the delays, expense and difficulty
involved in proving OWNER’S actual losses in a legal proceeding. Accordingly, and
instead of requiring such proof of loss or damage, OWNER and CONTRACTOR agree
00500 - 6
OWNER-CONTRACTOR
Community Civic Campus, Phase 1 Police Station AGREEMENT
that for each calendar day's delay beyond the Scheduled Completion Date, (which
delays are not excused pursuant to Section 3.3 of this Agreement), CONTRACTOR
shall pay to OWNER the amount of $2,500.00
00500 - 7
OWNER-CONTRACTOR
Community Civic Campus, Phase 1 Police Station AGREEMENT
B. Prevailing Wage Compliance
OWNER and CONTRACTOR recognize that CONTRACTOR’s breach of applicable
prevailing wage provisions, including those applicable through the California Labor
Code and OWNER’s additional prevailing wage compliance provisions within this
Contract (Article IV of the Owner-Contractor Agreement and Article 17 of the General
Conditions), will cause the OWNER damage by undermining OWNER’s goals in
assuring timely payment of prevailing wages, and will cause the OWNER additional
expense in obtaining compliance and conducting audits, and that such damage would
not be remedied by CONTRACTOR’s payment of restitution to the worker paid less than
the prevailing wage. OWNER and CONTRACTOR further recognize the delays,
expense and difficulty involved in proving OWNER’s actual losses in a legal proceeding.
Accordingly, and instead of requiring such proof of loss or damage, OWNER and
CONTRACTOR agree that for each instance where Owner has determined that
prevailing wage requirements were not met, CONTRACTOR shall pay to OWNER as
liquidated damages the sum of three (3) times the difference between the actual amount
of wages paid and the prevailing wage which should have been paid.
ARTICLE IV
PREVAILING WAGES
Reference is made to the requirements on the general prevailing wage rates set forth in
the General Conditions of the Contract Documents. Those rates are hereby specified as
the minimum rates of prevailing wage to be paid workers under this Contact.
This Project is a Public Work, subject to Labor Code §1771. The general
prevailing rate of per diem wages and the general prevailing rate for holiday and
overtime work in this locality for each craft, classification, or type of worker needed to
execute this Agreement is that ascertained by the Director of the Department of
Industrial Relations of the State of California. The Prevailing Rate Schedules shall be
made available to any interested party on request. The holidays upon which such rates
shall be paid shall be all holidays recognized in the collective bargaining agreement
applicable to the particular craft, classification or type of worker employed on the
PROJECT. CONTRACTOR shall post the Prevailing Rate Schedule at the Site.
The wages to be paid for a day's work to all classes of laborers, workers, or
mechanics on the work contemplated by this contract, shall be not less than the minimum
wage rate described in the Notice to Bidders as applicable to this contract. Each laborer,
worker or mechanic employed by a CONTRACTOR or by any subcontractor shall receive
the wages herein provided for. The CONTRACTOR shall pay forty dollars ($40) per day
penalty for each worker paid less than prevailing rate of per diem wages unless the failure
of the contractor or subcontractor to pay the correct rate of per diem wages was a good
faith mistake and, if so, the error was promptly and voluntarily corrected when brought to
00500 - 8
OWNER-CONTRACTOR
Community Civic Campus, Phase 1 Police Station AGREEMENT
the attention of the contractor or subcontractor. The penalty may not be less than eighty
dollars ($80) for each calendar day, or portion thereof, for each worker paid less than the
prevailing wage rate, if the contractor or subcontractor has been assessed penalties
within the previous three years for failing to meet its prevailing wage obligations on a
separate contract, unless those penalties were subsequently withdrawn or overturned.
The penalty may not be less than one hundred twenty dollars ($120) for each calendar
day, or portion thereof, for each worker paid less than the prevailing wage rate, if the
Labor Commissioner determines that the violation was willful, as defined in subdivision
(c) of Section 1777.1. The difference between the prevailing rate of per diem wages and
the wage paid to each worker shall be paid by the Contractor to each worker.
The general prevailing wage rates determined by the Director of Industrial
Relations are available at the California Department of Industrial Relations website at
http://www.dir.ca.gov, at the County of San Mateo and at the Office of the City Engineer
located at:
City of South San Francisco
315 Maple Avenue
South San Francisco, CA 94080
CONTRACTOR shall comply with the payroll records requirements set forth in
Section 17.2 of the General Conditions and the provisions in Section 7.10 of the
General Conditions concerning apprentices and shall be responsible for causing all of
CONTRACTOR's subcontractors to comply with these requirements and provisions.
In addition to the California Labor Code requirements, OWNER recognizes that
CONTRACTOR’s payment of prevailing wages promotes the following goals:
1. Protection of job opportunities within the City of South San Francisco and
stimulation of the economy by reducing the incentive to recruit and pay a substandard
wage to workers from distant, cheap-labor areas;
2. Benefiting the public through the superior efficiency and ability of well-paid
employees, thereby avoiding the negative impact that the payment of inadequate
compensation has on the quality of services because of high turnover and instability in
the workplace;
3. Payment of a wage that enables workers to live within the community, thereby
promoting the health and welfare of all citizens of South San Francisco by increasing
the ability of such workers to attain sustenance, avoid poverty and dependence on
taxpayer funded social services; and
4. Increasing competition by promoting a level playing field among contractors with
regard to the minimum prevailing wages to be paid to workers.
00500 - 9
OWNER-CONTRACTOR
Community Civic Campus, Phase 1 Police Station AGREEMENT
The CITY will not recognize any claim for additional compensation because of the
payment by the CONTRACTOR for any wage rate in excess of prevailing wage rate set
forth in the contract. The possibility of wage increases is one of the elements to be
considered by the Contractor in determining the CONTRACTOR’s bid, and will not, under
any circumstances be considered as the basis of a claim against the CITY on the contract.
An error on the part of an awarding body does not relieve the CONTRACTOR from
responsibility for payment of the prevailing rate of per diem wages and penalties
pursuant to Labor Code Sections 1770-1775.
ARTICLE V
NON-DISCRIMINATION
In the performance of this contract the CONTRACTOR will not refuse or fail to
hire or employ any qualified person, or bar or discharge from employment any person,
or discriminate against any person, with respect to his compensation, terms, conditions
or privileges of employment, because of such person's race, color, religion, creed,
national origin, ancestry, ethnicity, disability, age, marital status, sex, sexual orientation,
or actual or perceived gender identity. If the CONTRACTOR or any of his
subcontractors shall be found in violation of the above nondiscrimination provision, the
CONTRACTOR shall be deemed to be in material breach of this Agreement and
thereupon the OWNER shall have the power to do all or any of the following: (1) to
cancel or suspend this Agreement, in whole or in part, and (2) to deduct and retain from
the amount payable to the CONTRACTOR the sum of $250.00 for each person
discriminated against in the performance of this Agreement for each calendar day
during which such person was discriminated against in the performance of this
Agreement, as liquidated damages for such breach of this Agreement, provided that the
number of persons discriminated against shall not be deemed, for the purpose of
determining the amount of such damages only, to exceed the number of positions in
connection with which such discrimination occurs, e.g., if 20 persons are improperly
discriminated against in connection with five positions, then the multiple use in
assessing damages shall be the number of positions (5) and not the number of persons
(20) discriminated against. In the event such finding is made after completion of the
contract and after payment of all sums due CONTRACTOR by OWNER,
CONTRACTOR shall be obligated to pay said sum to OW NER upon demand by
OWNER. Violations of said provisions by subcontractors shall for the purposes of this
provision be deemed to be violations by the CONTRACTOR. The CONTRACTOR shall
not be deemed to be in breach of the provisions of this paragraph unless the State Fair
Employment Practices Commission, or an appropriate Federal commission or agency,
or a court of the State of California or of the United States Government finds, in any
action or proceeding to which CONTRACTOR is a party, that the CONTRACTOR or a
subcontractor discriminated against one or more specifically named employees or
applicants for employment because of race, color, religion, creed, national origin,
ancestry, ethnicity, disability, age, marital status, actual or perceived gender identity,
sex or sexual orientation in the performance of this Agreement; provided that such court
00500 - 10
OWNER-CONTRACTOR
Community Civic Campus, Phase 1 Police Station AGREEMENT
has issued a final judgment in such action or proceeding, or that the Fair Employment
Practices Commission has issued a final order pursuant to Section 1426 of the Labor
Code, or has obtained a final injunction pursuant to Section 1429 of the Labor Code, or
that said appropriate Federal commission or agency has issued a final order or obtained
a final injunction, and provided further, that for the purpose of this paragraph, no
judgment, order, decree or injunction shall be considered final during the period within
which (1) appeal may be taken, or (2) the same has been stayed by order of court, or
(3) further proceedings for vacation, reversal or modification are in progress before a
competent administrative or judicial tribunal.
The CONTRACTOR shall include the provisions of the above paragraph in every
subcontract or purchase order so that such provision shall be binding upon each of his
subcontractors and vendors.
ARTICLE VI
WORKER'S COMPENSATION INSURANCE
By my signature hereunder, as CONTRACTOR, I certify that I am aware of the
provisions of Section 3700 of the Labor Code which require every employer to be
insured against liability for Worker's Compensation or to undertake self-insurance in
accordance with the provisions of that Code, and I will comply with such provisions
before commencing the performance of the WORK of this Agreement.
ARTICLE VII
CONFLICT
In the event of conflict between the terms of this Agreement and the bid or
proposal of said CONTRACTOR, then, this Agreement shall control and nothing herein
shall be considered as an acceptance of the terms of the proposal conflicting herewith.
ARTICLE VIII
EXHIBITS
This Agreement includes the following Exhibits, which are attached hereto and
incorporated herein by reference:
Exhibit A The Site
Exhibit B Contract Documents
Exhibit C Contract Sum
00500 - 11
OWNER-CONTRACTOR
Community Civic Campus, Phase 1 Police Station AGREEMENT
IN WITNESS WHEREOF, the parties to these presents have hereunto set their
hands the day and year first hereinabove written.
APPROVED AS TO FORM: THE CITY OF SOUTH SAN FRANCISCO
_____________________ By___________________________
City Attorney City Manager
SWINERTON BUILDERS_________
(CONTRACTOR Name)
By ___________________________
Its___________________________
By ___________________________
Its___________________________
Employer ID Number _____________
Contractor's License No. _________
Expiration Date: ________________
City Business License No.:__________
Expiration Date:__________________
00500
EXHIBIT A to
South San Francisco Measure W OWNER-CONTRACTOR
Community Civic Campus AGREEMENT
EXHIBIT A
SITE MAP
(Reference drawing sheet CP3.01)
00500
EXHIBIT B to
South San Francisco Measure W OWNER-CONTRACTOR
Community Civic Campus AGREEMENT
EXHIBIT B
CONTRACT DOCUMENTS
1. Owner-Contractor Agreement
2. General Conditions
3. Contractor’s Performance Bond
4. Contractor’s Labor and Material Payment Bond
5. Project Plans
6. Project Specifications
7. Addenda, Substitutions, Modifications, Change Orders
8. List of Subcontractors, Suppliers, Truckers and Brokers (Non-Federally Funded
Projects)
9. Instructions to Bidders
END OF EXHIBIT B
00500
EXHIBIT B to
South San Francisco Measure W OWNER-CONTRACTOR
Community Civic Campus AGREEMENT
EXHIBIT C
CONTRACT SUM
A. BASE PRICE
Lump sum price for the furnishing of all labor, materials, services, equipment,
fringe benefits, taxes, insurance, overhead and profit and any other costs or
expenses necessary to perform all of the Work:
FORTY SEVEN MILLION FOUR HUNDRED NINETY SIX THOUSAND SIX
HUNDRED EITHTY FIVE AND NO/100 DOLLARS
($_47,496,685.00_______________)
B. Hazardous Material Abatement (per Appendix E)
SIXTY SIX THOUSAND SIX HUNDRED FIFTEEN AND NO/100 DOLLARS
($_66,615.00__________________)
C. ALLOWANCES – Not Used
D. ALTERNATES
1. Deductive Alternate #1 ($18,000.00)
2. Deductive Alternate #2 ($15,000.00)
E. TOTAL CONTRACT SUM:
FORTY SEVEN MILLION FIVE HUNDRED THIRTY THOUSAND, THREE
HUNDRED AND NO/100 DOLLARS
($47,530,300_________________)
F. UNIT PRICING
END OF EXHIBIT C
END OF SECTION 00500